Terms and Conditions

These Terms and Conditions govern your access to and use of this website and any related pages, forms, content, service descriptions, estimate requests, contact tools, calls-to-action, and digital resources operated for Blue Works HVAC, a Blue Works Company service offering. For purposes of these Terms, “Blue Works,” “Blue Works HVAC,” “Company,” “we,” “our,” and “us” refer to Blue Works Company and its HVAC, mechanical, plumbing, pipe restoration, and related service operations. “You,” “your,” “visitor,” “customer,” “property owner,” “facility manager,” and “user” refer to any person or entity accessing this website or communicating with us through it.

By accessing this website, submitting a form, requesting service, calling us from this website, emailing us, using any online feature, or continuing to browse this website, you agree to be bound by these Terms and Conditions. If you do not agree, you should not use this website.

1. Company Information

Blue Works Company provides HVAC, mechanical system support, plumbing, pipe lining, pipe cleaning, pipe inspection, pipe restoration, and related services in Florida and, where applicable, on larger projects outside local service areas.

Main Phone: (877) 258-3664

Email: team@blueworkscompany.com

Orlando Office:
9187 Boggy Creek Road
Orlando, Florida 32824

Florida State Licenses:
CFC1433187
CGC1536940
CMC1251435

References to licensing, certifications, experience, service capabilities, project history, warranties, or service availability on this website are provided for general informational purposes. Actual licensing applicability, scope of work, project requirements, permitting, code compliance, warranty availability, and responsibility for any specific service depend on the job, contract, jurisdiction, property condition, and final written agreement.

2. Website Purpose

This website is intended to provide general information about Blue Works HVAC services, including but not limited to commercial HVAC service, HVAC repair, HVAC replacement, preventative maintenance, airflow correction, rooftop units, packaged equipment, split systems, ventilation issues, humidity control, mechanical system performance support, and related building system services.

The website may also reference Blue Works Company’s broader services, including plumbing, pipe inspection, pipe cleaning, pipe lining, pipe replacement, commercial mechanical service, trenchless pipe rehabilitation, sewer inspection, sewer cleaning, water piping, storm drains, vertical piping, sovent systems, and related restoration services.

The information on this website is not a substitute for an on-site inspection, technical diagnosis, engineering review, written proposal, signed contract, permit review, manufacturer documentation, code interpretation, or professional judgment specific to your property.

3. No Automatic Contractor-Client Relationship

Your use of this website does not create a contractor-client relationship, service agreement, maintenance agreement, emergency service obligation, consulting relationship, fiduciary relationship, partnership, agency relationship, or any other professional relationship with Blue Works.

A binding service relationship is created only when Blue Works accepts the work in writing, issues an approved proposal, enters into a written agreement, accepts a work order, dispatches service under agreed terms, or otherwise confirms the engagement through an authorized representative.

Submitting a website form, leaving a voicemail, sending an email, requesting an estimate, using a contact button, or calling from the website does not guarantee acceptance of work, service availability, same-day response, pricing, scheduling priority, emergency dispatch, or any specific result.

4. Service Information Is General

All descriptions of HVAC, mechanical, plumbing, piping, inspection, cleaning, restoration, lining, maintenance, repair, replacement, or diagnostic services are provided for general informational and marketing purposes only.

Actual service recommendations may vary based on many factors, including but not limited to:

• Property type and use;
• System age, model, condition, capacity, and installation history;
• Access limitations;
• Electrical, structural, roofing, plumbing, drainage, ventilation, or mechanical conditions;
• Prior repairs or modifications;
• Code requirements;
• Permitting requirements;
• Manufacturer requirements;
• Site safety conditions;
• Weather conditions;
• Availability of equipment, parts, materials, labor, lifts, cranes, subcontractors, or specialty vendors;
• Customer approvals and payment terms;
• Conditions discovered after work begins.

Blue Works does not guarantee that any service described on this website is appropriate, available, permitted, warrantied, or sufficient for your specific property unless confirmed in a written proposal or agreement issued by Blue Works.

5. Estimates, Quotes, Pricing, and Proposals

Any pricing, estimate language, offer language, savings statement, “free estimate” statement, value statement, budget range, or cost-related content on this website is informational only unless included in a written proposal issued by Blue Works and accepted according to its terms.

Website content does not constitute a binding quote, fixed price, guaranteed price, bid, contract, or promise to perform work for any specific amount.

Blue Works may require an inspection, diagnostic visit, site walk, system evaluation, document review, engineering review, camera inspection, mechanical assessment, load calculation, permit review, or additional discovery before pricing can be finalized.

Blue Works reserves the right to revise, withdraw, reject, or condition any estimate or proposal before contract execution. Estimates and proposals may expire according to their stated terms or, if no expiration is stated, at Blue Works’ discretion.

6. Website Forms and Submitted Information

If you submit a form through this website, you agree to provide accurate, current, and complete information. You should not submit false information, misleading information, fraudulent requests, impersonation attempts, spam, abusive content, illegal content, or information that you do not have the right to provide.

You authorize Blue Works to use the information you submit to contact you, evaluate your request, schedule service, prepare a response, provide an estimate, route the inquiry internally, maintain business records, improve service operations, and perform related administrative functions.

Submitting information through this website does not guarantee that Blue Works will accept the job, provide service, respond within a particular time, or enter into any agreement.

You should not submit confidential, sensitive, proprietary, medical, financial, protected, or legally privileged information through a website form unless specifically requested by Blue Works through a secure and appropriate method.

7. Communications Consent

By submitting your phone number, email address, property address, company name, or other contact information through this website, you authorize Blue Works and its representatives to contact you regarding your inquiry, service request, estimate request, appointment, project, account, or related business matter.

Communications may occur by phone, email, text message, voicemail, mail, or other reasonable business communication methods. Message and data rates may apply for text messages or mobile communications.

You may request that we stop certain communications, but Blue Works may still communicate with you as necessary for active projects, legal obligations, safety matters, billing, collections, warranty issues, appointment coordination, or other legitimate business purposes.

8. No Emergency Guarantee

This website may contain urgent service language, service request forms, call buttons, or statements encouraging visitors to contact Blue Works for help. However, this website is not an emergency dispatch system.

Blue Works does not guarantee immediate response, emergency response, 24-hour availability, same-day service, after-hours service, or priority scheduling unless expressly confirmed in writing by an authorized Blue Works representative.

If you are experiencing an emergency involving fire, carbon monoxide, gas odor, electrical hazard, flooding, structural danger, medical danger, active injury, or any condition that may threaten life, health, or property, call 911 or the appropriate emergency authority immediately. Do not rely on this website as your emergency contact method.

9. HVAC and Mechanical System Risks

HVAC and mechanical systems can involve electrical components, refrigerants, moving parts, rooftop equipment, condensate drainage, ventilation, indoor air quality concerns, humidity issues, controls, duct systems, combustion equipment, access hazards, and other conditions that may pose risks if improperly handled.

You agree not to rely on website content as instructions for self-repair, diagnosis, installation, disassembly, refrigerant handling, electrical work, rooftop access, confined space access, plumbing work, gas work, duct modification, drain clearing, or any other technical activity.

Only qualified professionals should inspect, diagnose, service, repair, replace, install, or modify HVAC, mechanical, electrical, plumbing, refrigerant, gas, drainage, roofing, ventilation, or related systems.

10. No Professional Engineering or Design Advice

Unless expressly stated in a signed written agreement, website content does not constitute professional engineering advice, architectural advice, mechanical design advice, code consulting, legal advice, insurance advice, environmental advice, or manufacturer-specific technical guidance.

Any information about airflow, system performance, humidity control, ventilation, rooftop units, packaged systems, split systems, commercial equipment, pipe systems, mechanical piping, drainage, system restoration, or building conditions is general in nature and must be evaluated in the context of the actual property and applicable requirements.

11. Permits, Codes, and Regulatory Requirements

HVAC, mechanical, plumbing, piping, drainage, and construction-related work may be subject to permits, inspections, codes, licensing requirements, manufacturer requirements, utility requirements, fire safety requirements, building rules, property management requirements, and local jurisdictional approvals.

Blue Works will determine its permitting responsibilities for accepted work according to the written scope, applicable law, jurisdictional requirements, and project conditions. You are responsible for providing accurate property information, ownership or authorization information, access information, and any required approvals from landlords, associations, management companies, boards, tenants, municipalities, or other controlling parties.

Blue Works is not responsible for delays, increased costs, rejected inspections, redesign requirements, access denials, utility conflicts, hidden conditions, code compliance issues, customer-supplied information errors, or third-party approval issues unless otherwise stated in a written agreement.

12. Commercial, Industrial, Government, Multi-Unit, and Managed Properties

For commercial, industrial, government, healthcare, hospitality, high-rise, multi-unit, condominium, apartment, municipal, school, institutional, retail, restaurant, office, warehouse, and managed properties, service may require additional coordination.

You are responsible for notifying Blue Works of all relevant property rules, access restrictions, insurance requirements, safety requirements, certificate requirements, background check requirements, security rules, quiet hours, tenant notification requirements, shutdown windows, roof access requirements, loading dock rules, elevator rules, parking rules, union requirements, purchasing rules, and other site-specific conditions before work is scheduled.

Blue Works may decline, pause, reschedule, reprice, or condition service if site conditions, access conditions, safety conditions, authorization issues, or customer-provided information differ from what was represented.

13. Customer Authorization

By requesting service, you represent that you are the property owner, authorized representative, tenant with authority, facility manager, project manager, purchasing agent, board representative, general contractor, property manager, or other person with legal authority to request the work.

You agree to indemnify and hold Blue Works harmless from claims, losses, disputes, access issues, payment disputes, property disputes, ownership disputes, tenant disputes, management disputes, or authority disputes arising from your lack of authority or inaccurate representations.

14. Access to Property

You are responsible for providing safe, reasonable, and timely access to the property, equipment, roof areas, mechanical rooms, electrical panels, water sources, drains, ceilings, walls, crawlspaces, parking areas, loading areas, tenant spaces, and other work areas required for inspection, diagnosis, service, repair, replacement, or installation.

Blue Works may charge for delays, return trips, inaccessible equipment, locked areas, missed appointments, failed access, unsafe conditions, incomplete shutdown preparation, or other customer-caused scheduling inefficiencies, where permitted by the applicable proposal, agreement, or law.

15. Site Conditions and Hidden Conditions

Existing buildings and mechanical systems may contain hidden, concealed, deteriorated, damaged, unsafe, non-code-compliant, improperly installed, previously modified, inaccessible, or unknown conditions. These may include but are not limited to concealed leaks, electrical defects, structural issues, roofing defects, drain restrictions, mold-like growth, corrosion, insulation damage, duct leakage, improper prior repairs, equipment defects, refrigerant leaks, control failures, collapsed piping, damaged supports, abandoned lines, or code deficiencies.

Blue Works is not responsible for hidden or pre-existing conditions unless expressly agreed in writing. Discovery of hidden conditions may require additional work, additional charges, schedule changes, revised recommendations, third-party specialists, engineering review, permit revisions, customer approvals, or project suspension.

16. Existing Equipment and System Performance

Blue Works may service, repair, inspect, maintain, replace, or recommend changes to existing equipment or systems. Existing systems may fail, degrade, leak, stop operating, or reveal additional problems during or after inspection, maintenance, cleaning, repair, or startup.

Unless expressly stated in a written warranty or agreement, Blue Works does not guarantee the future performance, capacity, efficiency, lifespan, energy cost, indoor comfort level, humidity level, airflow balance, or reliability of existing equipment or systems.

Recommendations made by Blue Works are based on available information at the time of inspection or service. Conditions may change, and additional problems may become visible only after work begins or after equipment is operated under load.

17. Manufacturer Warranties and Third-Party Products

Equipment, parts, controls, materials, and components may be subject to manufacturer warranties, distributor terms, registration requirements, maintenance requirements, installation conditions, exclusions, and limitations.

Blue Works does not control manufacturer warranty decisions, manufacturer processing times, parts availability, discontinued products, warranty approvals, warranty denials, manufacturer labor exclusions, shipping delays, distributor delays, or changes in third-party product terms.

Any manufacturer warranty is separate from any written workmanship warranty issued by Blue Works. Warranty coverage must be confirmed in writing and may be subject to exclusions, maintenance obligations, misuse exclusions, access requirements, payment status, and other conditions.

18. Blue Works Warranties

No warranty is created by this website. Any warranty offered by Blue Works must be stated in a written proposal, written agreement, invoice, warranty document, or other written instrument issued by Blue Works.

Any website statement about being insured, certified, warrantied, code compliant, engineer approved, experienced, or qualified is general company information and does not create a specific warranty for your project.

Unless expressly provided in a written agreement, Blue Works disclaims all implied warranties to the fullest extent permitted by law, including implied warranties of merchantability, fitness for a particular purpose, habitability, non-infringement, and suitability.

19. Maintenance Requirements

HVAC, mechanical, plumbing, drainage, and pipe systems require proper maintenance. Failure to maintain equipment or systems may result in reduced efficiency, system failure, water damage, mold-like growth, odor, comfort complaints, increased energy use, premature equipment failure, warranty denial, and additional repair costs.

Blue Works is not responsible for damage, performance issues, warranty loss, system failure, or increased costs caused by lack of maintenance, improper maintenance, unauthorized repairs, customer misuse, tenant misuse, power issues, storm events, flooding, roof leaks, drain blockage, improper filters, blocked airflow, chemical exposure, corrosive environments, or third-party work.

20. Website Content Accuracy

Blue Works makes reasonable efforts to keep website content accurate and current. However, website content may contain errors, omissions, outdated information, typographical errors, incomplete descriptions, broken links, outdated images, outdated service descriptions, or information that does not apply to every property or service area.

Blue Works may update, remove, edit, reorganize, or replace website content at any time without notice.

We do not warrant that website content is complete, accurate, current, uninterrupted, secure, error-free, or suitable for your specific purpose.

21. Photos, Videos, Project Examples, and Case Studies

Photos, videos, project descriptions, case studies, before-and-after examples, diagrams, illustrations, icons, graphics, animations, and service examples are provided for general informational and marketing purposes only.

They may not represent your property, your system, your equipment, your job conditions, your pricing, your project timeline, your outcome, or your warranty. Past project results do not guarantee future results.

Some images may be representative, staged, edited, cropped, licensed, generated, enhanced, or selected to communicate a general service concept. Actual field conditions may differ.

22. Reviews, Testimonials, and References

Any reviews, testimonials, references, ratings, customer comments, or third-party badges displayed or referenced on this website are provided for general informational purposes. They reflect individual experiences and do not guarantee that every customer will have the same experience.

Blue Works may display, quote, summarize, link to, or reference reviews and testimonials from customers or third-party platforms where permitted. Third-party review platforms are not controlled by Blue Works, and their content, availability, scoring, policies, or display methods may change without notice.

23. Intellectual Property

All website content, including text, layout, structure, graphics, logos, trademarks, service marks, icons, images, videos, code, design elements, page organization, copy, service descriptions, forms, branding, slogans, and other materials are owned by Blue Works, licensed to Blue Works, or used with permission, unless otherwise stated.

You may view and print reasonable portions of the website for personal or internal business evaluation purposes only. You may not copy, scrape, reproduce, republish, sell, license, distribute, mirror, frame, modify, create derivative works from, or commercially exploit website content without written permission from Blue Works.

Unauthorized use of Blue Works names, marks, logos, content, images, service descriptions, or branding is prohibited.

24. Prohibited Website Use

You agree not to use this website for any unlawful, abusive, harmful, deceptive, disruptive, or unauthorized purpose.

Prohibited conduct includes but is not limited to:

• Submitting false, misleading, fraudulent, or impersonated information;
• Attempting to interfere with website security or functionality;
• Using bots, scrapers, crawlers, automated tools, or data extraction systems without permission;
• Uploading or transmitting malicious code, malware, viruses, spam, or harmful files;
• Attempting to gain unauthorized access to website systems, forms, databases, servers, analytics, email systems, or accounts;
• Harassing, threatening, abusing, defaming, or impersonating Blue Works employees, customers, vendors, or representatives;
• Using the website to solicit unrelated services, send spam, or conduct competitive scraping;
• Copying website content for a competing business;
• Interfering with the website’s operation, hosting, tracking, security, or performance;
• Violating any applicable law, regulation, or third-party right.

Blue Works may restrict, block, log, investigate, or report prohibited activity where appropriate.

25. Third-Party Links and Platforms

This website may link to third-party websites, platforms, social media pages, review profiles, maps, videos, vendors, manufacturers, trade organizations, payment processors, scheduling tools, analytics services, or other external resources.

Third-party websites and platforms are not controlled by Blue Works. We are not responsible for their content, accuracy, availability, security, privacy practices, terms, policies, fees, representations, or conduct.

Your use of third-party websites is at your own risk and subject to their own terms and policies.

26. Privacy, Cookies, and Tracking

Your use of this website may be subject to our Privacy Policy, Cookie Policy, Disclaimer, Accessibility Statement, Acceptable Use Policy, and any other website policies published by Blue Works.

Blue Works may use cookies, analytics, tracking tools, server logs, contact forms, call tracking, marketing measurement tools, and related technologies as described in applicable policies.

By using this website, you acknowledge that website activity may be collected, processed, stored, reviewed, or used for legitimate business purposes, including security, analytics, marketing measurement, service improvement, spam prevention, lead routing, customer support, and website maintenance.

27. Scheduling, Dispatch, and Service Availability

Service availability depends on location, staffing, workload, weather, equipment availability, parts availability, site conditions, customer approval, payment status, safety conditions, and project requirements.

Blue Works may accept, reject, delay, reschedule, cancel, or condition service requests at its discretion, subject to applicable law and any signed agreement.

Website references to service areas, cities, offices, or regions do not guarantee that service is available for every address or every type of work in that area.

28. Payment, Deposits, and Collections

Payment terms, deposits, progress payments, financing, retainage, late fees, collection rights, cancellation charges, mobilization charges, diagnostic fees, minimum charges, service call charges, and other financial terms are governed by the applicable written proposal, invoice, work order, service agreement, maintenance agreement, or contract.

Unless otherwise agreed in writing, you are responsible for payment for authorized work, diagnostic services, labor, materials, equipment, permits, rentals, subcontractors, specialty services, taxes, fees, return trips, delays, and approved change orders.

Blue Works may suspend, delay, or stop work for nonpayment, failed payment, credit concerns, disputed authorization, unsafe conditions, or other material issues, subject to applicable law and contract terms.

29. Change Orders and Additional Work

Any work outside the original written scope may require a change order, revised proposal, written authorization, additional payment, schedule adjustment, or additional terms.

Additional work may include but is not limited to hidden condition repairs, code upgrades, access work, equipment modifications, material substitutions, electrical work, roof access changes, structural supports, condensate corrections, drain repairs, controls work, duct modifications, crane or lift requirements, after-hours work, or additional diagnostics.

Blue Works is not obligated to perform additional work unless accepted according to its internal procedures and applicable contract terms.

30. Customer-Supplied Materials, Equipment, or Information

If you provide equipment, parts, controls, materials, drawings, specifications, reports, property information, prior inspection records, system data, or third-party recommendations, you are responsible for their accuracy, suitability, legality, completeness, and availability.

Blue Works may decline to install, use, rely on, or warranty customer-supplied equipment, parts, materials, or information.

Blue Works is not responsible for failures, delays, damages, warranty issues, code issues, compatibility problems, or performance problems caused by customer-supplied materials, customer-supplied equipment, customer-supplied information, third-party information, or prior work by others.

31. Safety

Blue Works may refuse, pause, or stop work if conditions are unsafe or unsuitable. Unsafe conditions may include but are not limited to electrical hazards, gas hazards, roof hazards, confined space hazards, biological hazards, sewage exposure, aggressive animals, blocked access, structural instability, weather hazards, violence, harassment, illegal activity, hazardous materials, or lack of required site control.

You agree to provide a safe work environment, disclose known hazards, secure pets, provide required access, notify occupants as needed, and cooperate with reasonable safety requirements.

32. Environmental, Mold, Air Quality, and Hazardous Material Issues

HVAC, plumbing, pipe, drainage, and building system issues may involve moisture, microbial growth, sewer gas, odors, contaminated water, asbestos-containing materials, lead, chemicals, refrigerants, insulation, dust, debris, or other environmental concerns.

Unless expressly stated in a written agreement, Blue Works does not provide environmental testing, mold remediation, asbestos abatement, lead abatement, hazardous material removal, laboratory analysis, medical advice, indoor air quality certification, or environmental consulting.

If suspected hazardous or regulated materials are encountered, work may need to stop until proper testing, remediation, abatement, or clearance is performed by qualified parties.

33. Limitation of Liability

To the fullest extent permitted by law, Blue Works, its owners, officers, managers, employees, contractors, subcontractors, vendors, licensors, affiliates, and representatives shall not be liable for indirect, incidental, consequential, special, punitive, exemplary, speculative, or enhanced damages arising from or related to your use of this website, reliance on website content, inability to access the website, service inquiries, scheduling issues, or website communications.

This limitation includes but is not limited to lost profits, lost revenue, lost business, lost data, loss of use, business interruption, tenant claims, customer claims, delay damages, reputational harm, equipment downtime, loss of comfort, or loss of opportunity, even if Blue Works has been advised of the possibility of such damages.

Nothing in these Terms is intended to limit liability where such limitation is prohibited by law.

34. Website Disclaimer

This website and all website content are provided on an “as is” and “as available” basis. Blue Works makes no warranty that the website will be uninterrupted, secure, error-free, virus-free, fully accurate, fully current, or available at all times.

Blue Works disclaims all warranties related to the website to the fullest extent permitted by law, including express warranties, implied warranties, warranties of merchantability, warranties of fitness for a particular purpose, warranties of non-infringement, and warranties arising from course of dealing or usage of trade.

35. Indemnification

You agree to defend, indemnify, and hold harmless Blue Works, its owners, officers, managers, employees, contractors, subcontractors, vendors, licensors, affiliates, and representatives from and against any claims, damages, liabilities, losses, costs, expenses, penalties, demands, causes of action, and fees, including reasonable attorneys’ fees, arising out of or related to:

• Your use or misuse of the website;
• Your violation of these Terms;
• Your submission of false, misleading, incomplete, or unauthorized information;
• Your lack of authority to request service;
• Your violation of any law or third-party right;
• Your misuse of Blue Works content, marks, images, or materials;
• Your failure to disclose property hazards, access limitations, or site conditions;
• Disputes involving ownership, tenants, landlords, boards, property managers, associations, contractors, or third parties connected to your request.

36. Force Majeure

Blue Works is not responsible for delays, failures, non-performance, interruption, increased costs, or inability to perform caused by events beyond its reasonable control.

These events may include but are not limited to hurricanes, tropical storms, flooding, lightning, extreme heat, natural disasters, fire, labor shortages, material shortages, supply chain delays, manufacturer delays, utility outages, road closures, government action, permitting delays, inspections delays, illness, accidents, equipment failure, cyber incidents, acts of war, terrorism, civil unrest, pandemics, or other conditions outside Blue Works’ reasonable control.

37. Governing Law

These Terms and any dispute arising from or related to this website shall be governed by the laws of the State of Florida, without regard to conflict-of-law principles.

38. Venue and Jurisdiction

To the fullest extent permitted by law, any dispute arising from or related to this website, these Terms, website communications, or website use shall be brought in the state or federal courts located in Florida, unless a different venue is required by applicable law or a signed written agreement.

For matters specifically tied to the Orlando office or work performed in the Orlando area, venue may be appropriate in Orange County, Florida, subject to applicable law and contract terms.

39. Dispute Resolution

Before filing a claim related to website use, you agree to make a reasonable good-faith effort to contact Blue Works and provide a written description of the dispute, including your name, contact information, property address if applicable, the relevant website interaction, and the relief requested.

This section does not prevent either party from seeking emergency injunctive relief, pursuing payment rights, preserving lien rights, responding to legal process, or taking action where delay would cause legal prejudice.

40. No Waiver

Blue Works’ failure to enforce any provision of these Terms does not constitute a waiver of that provision or any other provision. Any waiver must be in writing and signed by an authorized representative of Blue Works.

41. Severability

If any provision of these Terms is found invalid, unlawful, or unenforceable, the remaining provisions shall remain in full force and effect. The invalid or unenforceable provision shall be interpreted or modified to the minimum extent necessary to make it enforceable, where permitted by law.

42. Assignment

You may not assign or transfer your rights or obligations under these Terms without written permission from Blue Works.

Blue Works may assign, transfer, delegate, or subcontract its rights or obligations related to this website, business operations, service requests, marketing, hosting, analytics, administration, or customer communications where legally permitted.

43. Updates to These Terms

Blue Works may update these Terms at any time. The updated version will be posted on this website with a revised effective date. Your continued use of the website after updated Terms are posted means you accept the updated Terms.

You are responsible for reviewing these Terms periodically.

44. Related Policies

These Terms should be read together with any other policies published on this website, including:

• Privacy Policy;
• Cookie Policy;
• Disclaimer;
• Accessibility Statement;
• Acceptable Use Policy;
• Any proposal, estimate, invoice, warranty document, service agreement, or written contract issued by Blue Works.

If a signed written agreement between you and Blue Works conflicts with these website Terms, the signed written agreement controls for the specific project or service covered by that agreement.

45. Contact Information

Questions about these Terms may be directed to:

Blue Works HVAC / Blue Works Company
Orlando Office
9187 Boggy Creek Road
Orlando, Florida 32824

Main Phone: (877) 258-3664

Email: team@blueworkscompany.com

Florida State Licenses: CFC1433187, CGC1536940, CMC1251435